TIB Project Information

City of Lacey's Sleater Kinney Road SE

8-5-197(021)-1

8-5-197(021)-1
Sleater Kinney Road SE

Sleater Kinney Rd to 450' east on 6th Ave

FY 2002 Urban Arterial Program
Current Phase : Audit
Total TIB Funding : $816,811

County: Thurston   |   Legislative District: 22   |   Project Length: 0.09   |   TIB Engineer: Chris Langhoff   |   Last Payment Date: 10/27/2009

Project Information

Lead Agency LACEY
Funding Year 2002
Program UAP
Current Phase Audit
Legislative District 22
Congressional District 10
Federal Route Number 5265
Project Length 0.09 mi.
ADT 27,334
Functional Class Principal
Type of Work New Location
Project Contact Martin Hoppe
Contact Email mhoppe@ci.lacey.wa.us
TIB Engineer Chris Langhoff
Last Payment Date 10/27/2009

Project Schedule

  Target Date Actual Date
Project Selection Date   01/26/2001
Delayed Project Date 07/01/2005  
Predesign Approval
Design Approval 08/01/2001 09/25/2001
Bid Auth. Approval 09/30/2007 09/19/2007
Construction Approval 11/01/2007 10/29/2007
Project Closeout 12/15/2009 10/20/2009
Audit Date   10/27/2009
Withdrawn Date  

Project Funding

TIB Funds Project Costs
Environmental Study 0 0
Design Study 0 0
Total Predesign 0 0
     
Special Study 9,000 0
Design 92,400 182,789
Right of Way 195,000 761,714
Total Design 308,400 964,503
     
Construction Engineering 56,471 128,041
Construction Contract 451,940 924,068
Other Construction 0 13,915
Total Construction 508,411 1,066,024
     
Total TIB Funding 816,811 2,030,527

Local Funding Partners

Funding Amount Percent
LACEY 393,785 19.4%
WSDOT Funding 0 0.0%
Traffic Mitigation  303,788 15.0%
STP Funds  516,143 25.4%
 
 
 
 
 
 
Total Local Funding 1,213,716 59.3%

Project Description

This project will realign the east leg of 6th Avenue SE 100 feet to the south. The existing traffic signal will be removed and a new signal will be installed at the realigned intersection. Included in the project will be sidewalks, curbs and gutter, illumination, and landscaping.

Project Pictures

Project Delays

Delay Type Resolution Date Comments
Right Of Way Issues
Level 3 Board Delay
10/29/2007 City attempted to obtain ROW from Office Depot to enable realignment of 6th Avenue the court sided with Office Depot and denied the request. The city has been given until January 2007 to present a revised scope to the Board.

Project Payments